Key Grounds for EOT

• Force Majeure: Unforeseen events beyond the control of any party, such as natural disasters or political instability.
• Variations: Any changes in the scope of work, materials, or methods that increase the time needed for completion.
• Acts of the Employer: Delays caused by the employer, such as late provision of drawings or site access.
• Unforeseen Site Conditions: Conditions on the construction site that were not anticipated during planning, such as the discovery of archaeological remains or unexpected geological challenges.

Procedure for Applying for EOT

1. Notice of Delay: The contractor must notify the employer promptly of the cause and expected duration of the delay.
2. Submission of Claim: A formal EOT claim is submitted, outlining the delay’s cause, evidence supporting the claim, and the additional time required.
3. Employer’s Response: The employer reviews the claim and either accepts, rejects, or asks for further information.
4. Determination: The project manager or contract administrator assesses the claim based on the contract provisions and either grants the extension or refuses it.
5. Dispute Resolution: If the EOT is rejected, the contractor may have the right to escalate the issue to arbitration or litigation.

Our Services Include:

• Assessment of delay events: We help contractors assess whether delays qualify for an extension of time under the contract.
• Preparation of EOT claimss: We assist in preparing EOT claims, ensuring that all contractual and procedural requirements are met.
• Defense against EOT claims: We represent employers in contesting unjustified EOT claims.